Die Lieferung, Installation, Inbetriebnahme und Wartung von Maschinen zur Aufzeichnung evozierter Potenziale und eines EMG-Geräts für die Neurologie des CHU Liège für einen Zeitraum von 4 Jahren

✓Such as, the economically most advantageous tender is chosen based on three criteria: (1) Price (50 points) calculated by a proportional formula comparing to the lowest bid, considering base offer and required options (excluding preventive maintenance); (2) Technical value (40 points), broken down into four sub‑criteria of 10 points each for EMG, visual/auditory evoked potentials, somatosensory evoked potentials, and motor evoked potentials, assessed from documentation and tests; and (3) After‑sales services (10 points), evaluated on the proposed support organization (location and number of technicians, competencies, response and intervention times, spare parts availability, remote control capabilities, etc.).

✓Only regular offers are evaluated; the contracting authority may conduct negotiations and request a Best and Final Offer (BAFO), but minimum requirements and award criteria are not negotiable.

✓The documents also set out numerous risks and special conditions for bidders and the future contractor.

✓Such as, the bidder is bound by its offer for 120 days (for initial, negotiated and BAFO offers).

✓Subcontracting is allowed only with prior approval, at one level only, with the contractor remaining fully responsible; cession of the contract is prohibited without written authorization.

✓Strict penalties apply: €100 per calendar day of delay in delivery, €100 per day for breach of agreed intervention times in case of breakdown, and specific penalties of 4% of the initial contract amount per breach of data‑processing instructions or data‑protection obligations by subcontractors, in addition to statutory delay fines (0.1% per day, max 7.5% of order value).

✓The contractor may not slow or suspend execution even in case of payment delays or disputes (derogation to AR RGE art. 70; exception non adimpleti contractus excluded).

✓The bidder must also promptly provide demonstration equipment for testing (within seven days of request) on the specified sites, free consumables, and possibly bear insurance for test equipment.

✓Regarding contradictions or corrections within the documents, the text itself sets a mechanism for resolving them.

✓Such as, bidders are explicitly required, under art. 81 AR 18 April 2017, to signal any discordances, errors, incoherences or contradictions in the tender documents no later than 10 calendar days before the offer deadline, via the designated public forum, and to suggest missing characteristics or functionalities.

✓The tender states that all notices and corrigenda published in the Belgian Bulletin des Adjudications and relating to this market form an integral part of the special specifications, and the bidder is deemed to have taken them into account.

✓Where the special specifications derogate from general regulations (e.g.

✓AR RGE art. 70, payment deadlines), the special specifications expressly prevail and specify the applicable rule.

✓Similarly, the contract documents state that by submitting an offer, the bidder accepts all clauses of the cahier spécial des charges and renounces its own general conditions even if annexed, clarifying that in case of any conflict between bidder documentation and the tender documents, the tender documents apply.